The U.S. Court of Appeals, Eleventh Circuit is requesting Open Market Pricing to complete a project in Jacksonville, Florida. The project will consist of removal and installation of carpet, paint, vinyl wall base replacement, wallpaper removal, and wood touch-up. This request will be competitively bid among several vendors.

IMPORTANT: This Is a request for quote (RFQ). If you are unable to submit an offer, please indicate so on this form and return it to the Contracting Officer. 

Email your quote no later than the date and time specified above. Late quotes will not be considered unless the judiciary determines, at its own discretion, that considering the late quote is in the judiciary’s best interest and will not unduly delay the procurement. 

The Court intends to make a firm fixed-price award based on the lowest priced, technically acceptable quote. Vendors are urged to submit their best and final offer because no negotiations will take place after offers are received. 
This request does not commit the government to pay any costs incurred in the preparation of the submission of your offer or to contract for supplies or service should none of the vendors meet the necessary specifications. 

A Pre-Bid tour will be conducted on Thursday, February 20, 2025, 10:30 AM at 300 North Hogan Street, Jacksonville, Florida 32202.  Please meet in the lobby of the courthouse.  

Project Location: Bryan Simpson U.S. Federal Courthouse 300 North Hogan Street, Jacksonville, Florida 32202.

All questions concerning this RFQ must be submitted in writing by e-mail. All questions will be answered by email.
Sincerely,
Lauren Reese
Contracting Officer